# 6135--Uninterrupted Power Supply (UPS) Batteries

Notice 538b72aa738943919c691aeabeb5b4ce (solicitation 36C24427Q0009) from VETERANS AFFAIRS, DEPARTMENT OF, 244-NETWORK CONTRACT OFFICE 4 (36C244), posted 2026-09-30, responses due 2026-10-07T20:30:00.000Z. Status: open.

| Field | Value |
| --- | --- |
| Notice ID | 538b72aa738943919c691aeabeb5b4ce |
| Solicitation number | 36C24427Q0009 |
| Type | Sources Sought |
| Agency | VETERANS AFFAIRS, DEPARTMENT OF |
| Sub-tier | VETERANS AFFAIRS, DEPARTMENT OF |
| Office | 244-NETWORK CONTRACT OFFICE 4 (36C244) |
| Posted | 2026-09-30T15:56:37.000Z |
| Response deadline (UTC) | 2026-10-07T20:30:00.000Z |
| Set-aside | - |
| NAICS | 335910 |
| PSC | 6135 |
| Place of performance | Lebanon, USA |
| Award | - |

## Description

The Department of Veterans Affairs Lebanon VA Medical Center Sources Sought THIS IS NOT A SOLICITATION ANNOUNCEMENT. THIS IS A REQUEST FOR INFORMATION ONLY. This Request for Information (RFI) is intended for information and planning purposes only at this time; and shall not be construed as a solicitation or as an obligation on the part of the Department of Veterans Affairs. Because this is a Request for Information announcement, no evaluation letters and/or results will be issued to the respondents. This Sources Sought Notice is for market research purposes only and shall not be considered an Invitation for Bids, Request for Quotations, or a Request for Proposal. Do not submit a proposal or quote. This market research is issued for information and planning purposes only and does not constitute a solicitation nor does it restrict the Government as to the ultimate acquisition approach. Responses to this notice are not offers and cannot be accepted by the Government to form a binding contract. Additionally, there is no obligation on the part of the Government to acquire any products or services described in this Sources Sought notice. You will not be entitled to payment for direct or indirect costs that you incur in responding to this Sources Sought Notice. Any contract that might be awarded based on information received or derived from this market research will be the outcome of a competitive process. Interested parties are responsible for adequately marking proprietary, restricted or competition sensitive information contained in their response. No solicitation exists. Therefore, do not request a copy of a solicitation. VRLA Sealed, UPS12-400MR INTRODUCTION/BACKGROUND: The existing battery string for the Lebanon VAMC Radiology UPS is at its end-of-life and requires replacement to ensure optimal runtime and prevent critical equipment failure in the event of a power outage. In a crucial area like the Radiology department, this setup is standard and vital to protect sensitive imaging equipment, such as an MRI or CT Scanner to prevent data loss and allow for the safe completion of scans during a power failure.. OBJECTIVE: The Department of Veterans Affairs, VISN 04, Lebanon VA Medical Center hereby referred to as the Lebanon VAMC, is requesting acquisition of the following: Item Number Description Quantity 001 UPS12-400MR 12 Volt 40 EA 002 Installation, Testing/Calibration  and Off-site removal of batteries The contractor must provide this information with this Sources Sought. 1 EA 003 Delivery/Shipping 1 EA MAJOR REQUIREMENTS: The Contractor/Vendor must complete the following tasks to meet the needs of this acquisition: Salient Characteristics for Forty (40), VRLA Sealed, UPS12-400MR to include the following: 10 year design life at 25 C Absorbent Glass Mat (AGM) technology for efficient gas recombination of up to 99% and freedom from electrolyte maintenance. UL Recognized Flame- arresting vents in each Cell for safety and long life. Flame retardant polypropylene case and cover compliant with UL94V-2 Thermally welded case-to-cover bond to eliminate leakage. Can be operated in any orientation. Upright, side, or end mounting recommended. Not restricted for air transport Complies with IATA/ICAO Special Provisions A67. Not restricted for surface transport Classified as non-hazardous material as Related to DOT-CFR Title 49 parts 171-189. Not restricted for water transport - Classified as non-hazardous material per IMDG Amendment 27. Voltage: 12 AH 20 hr: 103 Weight lbs: 75.8 Weight kg: 34.4 Cells per Unit: 6 Max Discharge Current (AMPS): 800 Short Circuit Current: 5100 Ohms Impedance 60 Hz: .0025 Warranty: All equipment and materials must come with a standard three-year manufacturer(s) warranty. Warranty must begin after installation of equipment and completion of tests. Delivery/Installation: The contractor shall deliver and install all equipment required under this SON by November 1, 2026, unless otherwise directed by the Contracting Officer. Access to an unloading dock may not be available. A lift gate at destination is required. The contractor shall coordinate a kick-off meeting regarding delivery and installation with the facility POC within 21 calendar days of contract award. The contractor shall provide 72-hour notice prior to required delivery date to the facility POC. The Government requires this notice to ensure a Government-appointed subject matter expert and logistics personnel will be available at the site upon delivery. The contractor must provide all labor, materials, tools, equipment, and supervision needed to prepare for and complete the installation of the equipment in the space determined by the Government. Test and Acceptance: The contractor must test all equipment after installation. The Government will formally accept the equipment once installation and successful testing have been completed and approved in writing by the Government s appointed POC or subject matter expert. For this requirement, the contractor shall provide services for the following Uninterruptible Power Supply (UPS) system: Manufacturer: C & D Technologies Model Number: VRLA Sealed, UPS12-400MR Following the installation of the new batteries, the contractor is required to conduct a full functional test of the VRLA Sealed, UPS12-400MR UPS system to verify proper operation, voltage outputs, and battery backup capabilities. Additionally, as part of the technical proposal, responders must submit documented proof of previous experience, certifications, or past performance in successfully installing, maintaining, and testing this exact UPS model to be considered for this award. All hardware will be installed and operational in accordance with manufacturer s specifications and Lebanon VAMC Information Technology (IT) requirements. CONTRACTOR RESPONSIBILITIES: The contractor is responsible for the following: Qualified Personnel: The contractor must provide qualified personnel to perform the installation. Contracto

## Sources

- View on SAM.gov: https://sam.gov/opp/538b72aa738943919c691aeabeb5b4ce/view
- Data as of 2026-11-14. Source: https://sam.gov/data-services/Contract%20Opportunities/datagov

## Cite this

"6135--Uninterrupted Power Supply (UPS) Batteries, SAM.gov contract opportunity 538b72aa738943919c691aeabeb5b4ce." samgovapi.io, https://samgovapi.io/opportunity/538b72aa738943919c691aeabeb5b4ce, data as of 2026-11-14. Primary record: https://sam.gov/opp/538b72aa738943919c691aeabeb5b4ce/view

## API and MCP

- REST: GET https://samgovapi.io/api/v1/opportunities/538b72aa738943919c691aeabeb5b4ce
- MCP tool: get_opportunity

Independent. Not affiliated with, endorsed by or sponsored by GSA, SAM.gov or any U.S. government agency. Registering in SAM.gov is free at sam.gov.

Get a free API key: https://samgovapi.io/sign-up?ref=ai-claudebot